^Back To Top
foto1 foto2 foto3 foto4 foto5

Tender Documents

letterheadMOE

List of Tender Documents .

1. Click To Download Proposed Electronics Workshop Completion BOQ.  

 

TENDER NO: MTTI/PROPOSED ELECTRICITY AND ELECTRONICS WORKSHOP THIRD FLOOR COMPLETION WORKS/001-2018-2019

Michuki Technical Training Institute wishes to complete the construction works for the third floor in electrical and electronic workshop. Eligible contractors are hereby invited to tender for the construction works. Interested contractors should be registered as a building contractor with NCA category “5” and above and provide a tender security of kshs 30,000 from a reputable bank or insurance guarantee from the insurance firm approved by PPRA,valid for 150 days. Performance bond will only be provided by the tenderer for Kshs 100,000 for the person who will win the tender. They must attach a company profile which must contain copies of the following documents:

  1. Company registration documents
  2. NCA Registration certificate
  3. Valid tax compliance certificate
  4. Proof of work of similar magnitude and completely undertaken for the last five years.
  5. Proof of adequate equipment and key personnel for the specified types of work.
  6. Proof of sound financial standing and adequate access to bank credit line
  7. Litigation history of the court both in court and arbitration
  8. Fully completed Confidential business questionnaire
  9. Signed form of tender
  10. Audited financial statements for the last five years.

Further, tenders from the following tenderer shall be considered NON – RESPONSIVE and therefore subjected to automatic disqualification.

  1. A tender from a tenderer whose’ on-going project(s) is /are behind schedule and without any approved extension of time.
  2. A tender from a tenderer who has been severed with default notice on – going projects (s) or terminated in the previous projects.

A complete set of the tender documents can be viewed and downloaded for free from the institute website www.michukitech.ac.ke or obtained from the cash office upon payment of non- refundable fee of Ksh 1,000 in cash or bankers cheque payable to Michuki Technical Training Institute between 8.00 am and 5.00 pm on normal working days.

Complete tender documents put in plain sealed envelopes and marked PROPOSED ELECTRICITY AND ELECTRONICS WORKSHOP THIRD FLOOR COMPLETION WORKS/001-2018-2019should be deposited in the Tender Box at the Michuki Technical Training Institute on or before THURSDAY 3RD JANUARY 2019 at 10.00 am and be addressed to,

The Principal

Michuki Technical Training Institute

Tenders will be opened immediately thereafter in the presence of the tenderers or their representatives who choose to attend at Michuki T.T.I.’s boardroom at 10.00Am

Bidders are allowed to view the site at Michuki T.T.I.

 

2. Click To Download Proposed Perimeter Wall 210m Long BQ.

 

TENDER NO: MTTI/PROPOSED PERIMETER WALL PHASE 1 /002-2018-2019

Michuki Technical Training Institute wishes to construct a perimeter wall (210m long). Eligible contractors are hereby invited to tender for the construction works. Interested contractors should be registered as a building contractor with NCA category “5” and above and provide a tender security of kshs 30,000 from a reputable bank or insurance guarantee from the insurance firm approved by PPRA,valid for 150 days. Performance bond will only be provided by the tenderer for Kshs 100,000 for the person who will win the tender. They must attach a company profile which must contain copies of the following documents:

  1. Company registration documents
  2. NCA Registration certificate
  3. Valid tax compliance certificate
  4. Proof of work of similar magnitude and completely undertaken for the last five years.
  5. Proof of adequate equipment and key personnel for the specified types of work.
  6. Proof of sound financial standing and adequate access to bank credit line
  7. Litigation history of the court both in court and arbitration
  8. Fully completed Confidential business questionnaire
  9. Signed form of tender
  10. Audited financial statements for the last five years.

Further, tenders from the following tenderer shall be considered NON – RESPONSIVE and therefore subjected to automatic disqualification.

  1. A tender from a tenderer whose’ on-going project(s) is /are behind schedule and without any approved extension of time.
  2. A tender from a tenderer who has been severed with default notice on – going projects (s) or terminated in the previous projects.

A complete set of the tender documents can be viewed and downloaded for free from the institute website www.michukitech.ac.ke or obtained from the cash office upon payment of non- refundable fee of Ksh 1,000 in cash or bankers cheque payable to Michuki Technical Training Institute between 8.00 am and 5.00 pm on normal working days.

Complete tender documents put in plain sealed envelopes and marked PROPOSED PERIMETER WALL PHASE 1/002-2018-2019 should be deposited in the Tender Box at the Michuki Technical Training Institute on or before THURSDAY 3RD JANUARY 2019 at 10.00 am and be addressed to,

The Principal

Michuki Technical Training Institute

Tenders will be opened immediately thereafter in the presence of the tenderers or their representatives who choose to attend at Michuki T.T.I.’s boardroom at 10.00Am

Bidders are allowed to view the site at Michuki T.T.I.

 

3. Click To Download Kitchen Privatization Tender Document.

 

TENDER NO: MTTI/ PROVISION OF CATERING SERVICES/03/2018-2019

Michuki Technical Training Institute wishes to invite the public to tender for the provision of catering services

The qualified service provider must be:-

  1. A qualified Diploma Holder or above in the area of Food and Beverage.
  2. Able to prove that, he/she has offered the same services to the public or to the students.
  3. Certified as a food handler by the relevant bodies.
  4. Able to maintain quality and quantity of acceptable standards to the staff and students.
  5. Able to pay rent at a reasonable figure while taking care of all his/her staff salaries and other statutory deductions as may be required from time to time.

A complete set of the tender documents can be viewed and downloaded for free from the institute website www.michukitech.ac.ke or obtained from the cash office upon payment of non- refundable fee of Ksh 1,000 in cash or bankers cheque payable to Michuki Technical Training Institute between 8.00 am and 5.00 pm on normal working days.

Complete tender documents put in plain sealed envelopes and marked PROVISION OF CATERING SERVICES/03/2018-2019 should be deposited in the Tender Box at the Michuki Technical Training Institute on or before FRIDAY 4TH JANUARY 2019 at 10.00 am and be addressed to,

The Principal

Michuki Technical Training Institute

Tenders will be opened immediately thereafter in the presence of the tenderers or their representatives who choose to attend at Michuki T.T.I.’s boardroom at 10.00Am

 

 

For more details click on each Quotation to download the specification for each.

 

 

 

Copyright © 2013-2018. Web Developed by ICT Support Department Michuki Technical Training Institute Rights Reserved.


Facebook

University of NairobiICT